Opportunities / DEPT OF DEFENSE

LOWER BRULE NORTH SHORELINE STABILIZATION AND ECOSYSTEM RESTORATION, ELEMENT 2

Description (excerpt)

On or about 23 October 2026, the Government intends to issue the Invitation for Bid (IFB) for LOWER BRULE NORTH SHORELINE STABILIZATION AND ECOSYSTEM RESTORATION, ELEMENT 2. The IFB will close on or about 3 December 2026. This is a 100% Small Business Set-Aside. Sit Visit: A Site Visit is scheduled for 3 November 2026. Additional information regarding the site visit will be provided in the solicitation in Section 00 21 00. Project Description: Element 2 of the project includes the construction of a 100-foot-wide riparian planting bench, a gravel maintenance path along the entire reach, and the creation of a 200-by-1,500-foot island within Reach 4 of the lake, in water up to three feet deep. The island will be planted with cottonwood trees and other culturally significant vegetation. To protect the lakeward side of the island from wind, wave action, and ice erosion, a riprap revetment will be installed. The sheltered open water area between the island and the shoreline is anticipated to naturally evolve into approximately 5.17 acres of emergent wetland. Additionally, this measure will result in the creation of roughly 32 acres of riparian habitat. DO NOT submit requests for plans and specifications. See Obtaining Solicitation Documents below. Completion Date: The Contractor will be required to commence work upon receipt of contract award and complete the work 550 days after receipt of Notice to Proceed. This is subject to change after IFB issuance. Provisions will be included for liquidated damages in case of failure to complete the work in the time allowed. Performance and Payment Bonds will be required. Estimated Construction Costs: The estimated construction cost of this project is between $10,000,000 and $25,000,000. NAICS Code: The Primary North American Industry Classification System (NAICS) code anticipated for solicitation is 237990, Heavy and Other Civil Engineering Construction, with a size standard for Small Business of $45M. All contractors must be registered and have an active and verified account in the System for Award Management (SAM) in order to receive a contract award from any DoD activity. Contractors may access the Internet site at: https://www.sam.gov/ to register and/or obtain information about the SAM program. Contractors must ensure that the applicable NAICS listed above is included in their profile prior to submission of offer. Contracting Officer Address: USACE Omaha District 1616 capital Ave Omaha, NE 68102-4901 Point Of Contact: …

View the official notice on SAM.gov →